Essay on Happiest Place on Earth - 1065 Words

As the bus from the airport slowly comes to a halt, I jerk back in my seat with a grin from ear to ear. The time has really come again as I peer out the window and see the Welcome Home sign I long to see every year, in Disney World. Surrounded by the pale shades of blue on the buildings, the starry sky, and palm trees, I am once again at The Beach Club, my favorite resort in the Happiest Place on Earth. With a silent and still beauty surrounded by the cool evening breeze, the anticipation of the waking morning is too hard to handle, knowing that the magical feeling of the Magic Kingdom the next day will surround me. Beep! Beep! Beep! The no longer dreaded alarm clock sounds in the early morning. As I hear my parents groan,†¦show more content†¦Hopping into our space ship, we get the all-clear signal and exhilarate through darkness up the rackety hill to the launching pad. The countdown starts. 10, 9, 8, 7, 6, 5, 4, 3, 2, 1! We shoot down a hill into a swirl of turns as littl e stars illuminate the way through space. A gust of wind blows through my hair as my arms are waving, I scream my heart out. We make our way to Splash Mountain after fulfilling our craving of Mickey Mouse waffles and ice cream for breakfast. The hot waffle melts the ice cream, making this a fun but messy treat as the creamy treat melts into the sweet waffle. With a satisfaction in our bellies, our journey continues. We wait in line for what seems to be forever, but finally make our way into the cold tunnel where our rafts await. We embark on our journey through Brer Patch, experiencing mini drops, but nothing compared to what lies ahead. As the surroundings fade into blackness, evil laughter is heard. We plunge down the 50-foot drop, with a splash that consumes us, drenching everything from head to toe. Ready for our afternoon lunch, we go against the wave of crowds, as my parents and I jump onto the monorail, heading to EPCOT. Soaring through the sky, seeing blurs of green trees a nd cars, we glide through the resort and finally reach our destination. Walking through EPCOT, my mom turns back the clock and transforms into her inner child as we walk across the globe in the World Showcase, experiencing the savory tastes of culinaryShow MoreRelatedAnalysis Of Walt Disney s The Happiest Place On Earth 1159 Words   |  5 PagesBurden Mrs. Abbe English 6 1 May 2015 The Man, The Myth, The Legend A man by the name of Walt Disney, is the ideal symbol of an American hero. Disney is known to bring inspiration and imagination into many of his productions. Disneyland, the happiest place on earth, was built by Disney in the late forties. As the founder of Walt Disney Company, and a producer, he has collected a record of fifty- nine nominations as an Academy Award winner, winning thirty-two awards, and still holding the record. At sixty-fiveRead MoreAnalysis Of Disney U s The Happiest Place On Earth1566 Words   |  7 Pagesthrough a thought provoking journey of ground breaking leadership tactics, inventive training methods, and creating an engaging environment for an employee. Disneyland was Walt Disney’s dream of a theme park that would be, in his words, â€Å"The Happiest Place on Earth†. Walt understood too well that the people that were hired would need to be taught how to create that elusive atmosphere. He called on Van France to assist him in creating what has become a world renowned training program. This programRead MoreThe Land Of Pixie Dust And Fairytales The Happiest Place On Earth Essay1507 Words   |  7 PagesIntroduction The land of pixie dust and fairytales the Happiest Place on Earth and that mouse Walt Disney World is all this and more to the over 50 million visitors who pour through its gates every year. Prices may be high and the lines long, but you can learn to love Disney with a little know-how. When you see kids eyes light up as they meet Mickey or glimpse Cinderella Castle on the horizon, you ll no longer able be able to say that you don t like Disney. The Topic: Walt Disney World is aRead MoreHow the Happiest Place on Earth, Walk Disney Resort, was Built1864 Words   |  7 Pagesthe property. VoluntEARs is a program that was started in 1992 for Walt Disney employees who want to volunteer with a company, in exchange for monetary funds to their charity of choice. Disney believes that it makes their company a more desirable place to work and also reinforces the attractiveness of brands and entertainment. VoluntEARs strengthens the bonds with families as well as consumers, neighbors and business associates. Since the program’s founding, Disney VoluntEARs have given more thanRead MoreEssay on The Walt Disney Company and Hidden Mickey913 Words   |  4 Pagesable to identify three hidden secrets they probably did not know about Disneyland and also some history on the amusement park. Central Idea: The happiest place on earth has a few interesting facts that most people don’t know about. Organizational Method: Informative Introduction: Disneyland, opening in 1955, has become one of the happiest places on earth. With having close family in California, and growing up there practically, I have been able to experience Disneyland well over at least 15 timesRead MoreThe Variations Of Stability By Johnny Truant1738 Words   |  7 Pages When the reader is first introduced to Thumper she is having work done to a tattoo above her privates that reads â€Å"The Happiest place on earth†. The actual tattoo itself makes the reader pass judgement on her behavior regarding her sexual partners. It can be interpreted instead that she is claiming everybody who is sexually active with Thumper is in the happiest place on earth. It has been clear that Johnny and Thumper have not been sexually active with one another, meaning he wouldn’t be able toRead MoreDisneyland Profile725 Words   |  3 PagesProfile What does the â€Å"happiest place on earth,† also know as Disneyland, have to offer on a regular basis? It was a bright sunny day in Anaheim California, and my friends Ruben, Sassan and I were just arriving at the theme park. We were all so excited to spend the day messing around between parks; especially considering the fact that we got in for free! Ruben’s mom works at Disneyland, which is how we were able to get in for free. Disneyland is only one theme park, but there are so many differentRead MoreThe Idea Of Knowing Who I Am908 Words   |  4 PagesThe idea of knowing who I am is one I’ve struggled with greatly. Frankly speaking, I am still discovering who I am. Are there moments that have taken place which have led me to be close to figuring out my â€Å"true self†? Indeed there have certainly been moments where I am closer to figuring out my â€Å"true identity.† One such moment was when I realized my happiness depended upon myself. Personhood, in my own definition of it, is when one is truly their own person. There is no need to feel the obligationRead MoreSpeech Outline Disney World Essay1114 Words   |  5 PagesIntro: Attention getter: Disney World has always been known as the happiest place on earth. I went there as a kid and haven’t forgotten my experience since. (Talk about how you got sick) Disney World has touched the hearts of kids for more than 50 years. * 2 * 2 Many people have heard of Disney World and some have even visited there. But do these people know the many secrets that lie hidden. 1 1 Whether that is the history of Disney World, some of the favorites rides enjoyed , and interestingRead MoreMy Ideal At The Hospitality Industry1186 Words   |  5 Pagesperfected customer service and I believe that I would fit in to the Disney idea of putting the customer first. The Walt Disney World Mindset on Guest Relations â€Å"We create Happiness,† (Walker, 2016). This is the mission statement Disney has put in place to show their main priority. Disney bases their business on quality, service, and show. They want their guests to feel happy in all circumstances such as on a ride, during a dining experience, or even talking to a street sweeper on Main Street U.S

Contract Law Dictates Development Corporation

Question: Describe about the Contract Law Dictates for Development Corporation. Answer: The general principle of contract law dictates that when parties enter into a contract they are obligated and bound to effectively perform the contract within the agreed terms and conditions in the contract. It is worth noting that construction contracts have gained local notoriety in litigation because of delays that are always accompanied by excuses from the contractors. It is thus submitted that failure to perform a contract within the stipulated and agreed schedule attracts significant liability as was seen in Jerry Bennett Masonry, Inc. v. Crossland Constr.Co. (2005), where a subcontractor did not adequately provide for labor for a construction thereby causing a delay in the construction and the courts upheld delay damages against the company. Marina Construction Limited was notified of all the structural defects with the building in the contract as stated in the facts and therefore the delay was one that ought to have been foreseen before agreeing to the terms of the contract and formation of the contract. The delay can thus be termed as one that is an inexcusable delay which is defined as a delay caused by the fault or neglect of the contractor and the owner is entitled to a claim for damages. (Nathan, Lee, and Henry, 2014) Marina Construction Limited (MCL) is under a contractual obligation to perform the contract according to the agreed terms. However, in cases of delay in the performance of contracts the Western Australia Supreme court has held that a detailed notice of any such delay must be served to the other party. (CMA Assets Pty Ltd v John Holland Pty Ltd, 2015) It is not in dispute that MCL provided a notice to the principal in this case albeit it was orally made, the notice can be held to have been given out of time. In Australian Development Corporation (ADC) v White Constructions (1996) it was held that a notice of extension of time must be given within reasonable time to allow the principal take any remedial action or adjustments as to any adjustments. The notice by MCL was only served after the article in the newspaper was posted yet it was within the knowledge of the directors that they could not complete the contract as stipulated in the contract. It is imperative to note that a notice is required even where the contract has not provided for an extension clause. The university can claim liquidated damages if the contract had a liquidated damage clause. (J-Corp Pty Ltd v Mladenis (J-Corp), 2010) The liquidated damage clause will spare the university tedious endeavors calculating the amount of damages compensable. (Boucaut Bay Co Ltd v Commonwealth, 1927) On the other hand, the absence of a liquidated damage clause in a contract will not entitle the contractor to escape liability for delay damages to the contractor. The university can thus recover actual damages without the liquidated damage clause that includes lost profits from the admission of the students and rental charges and interests. The South Carolina Supreme Court affirmed that loss profits can be awarded where the owner undertakes to prove with a reasonable degree of certainty the amount of loss profits. (South Carolina Federal Savings Bank v. Thornton-Crosby, 1992) In regards to the $500,000 that the university had paid to MCl, the university can claim for the restitution of the funds that serves to protect it from unjust enrichment. Conversely, the courts have held in Fibrosa Spolka Akcyjna v Fairburn Lawson Combe Barbour Ltd (1943) that a party that had pre-paid some amounts of money for the performance of the contract could recover it after the contract had been frustrated. It is in fact submitted that the amount paid by the university should not have been given to MCL as this was rewarding them for their breach. 2. Tom, Jane Co (TJC) Firm was under the obligation to perform their duties in a professional manner. In the conduct of their duties and activities, the firm ought to have in mind the ripple effects of their actions on the persons they are serving. The famous dicta by Lord Atkin usefully asserts that one should take reasonable care to avoid acts or omissions that are likely to injure a neighbor and further defines a neighbor as one who is like to be affected by the consequences of ones acts or omissions.( Donoghue v. Stevenson, 1932). Moreover, the Civil liability Act 2002 recognizes the tort of professional negligence. It is submitted to TJC that their acts and omissions have invited the tort of negligence precipitated by their omissions that displayed any degree of complacency and ineptitude in their audit business. For an act or omission to amount to negligence there are three essential elements that the plaintiff, in this case, will have to prove for the action to be successful. (Grant v Australian Knitting Mills, 1936) It is essential that a duty of care owed to the claimant who is the consumer must exist and consequently a breach of that duty. In addition, there must also be shown that indeed there was damage or injury caused as a consequence of the breach of that duty. Duty of care The neighbor principle has since widened the scope of the duty of care and it must not necessarily be a consumable product but the duty of care also extends to instances where one relies on information or advice from someone with a specific skill and knowledge. It follows that where such information is given negligently a tort of negligence action can arise. (L Shaddock Associates Pty Ltd v Parramatta City Council, 1981) TJC has a duty of care to its clients sunflower bank limited and they are expected to perform there duties with skill and competence. They have a duty to exercise reasonable skill and care whereby the standard of skill expected is of an ordinary skilled person practicing the same discipline. (Bolam v Friern Hospital Management Committee, 1957). It is imperative to note that the test for test for determining the standard of care will be that of an ordinary skill person highlighted above, in the same practice. This test is commonly referred to as the bolam test. A modern litmus that would determine the duty of care was espoused in Caparo Industries v Dickman (1990) where a tripartite approach is given by the court. First, it was established that the damages and consequence of the acts of the defendants must be reasonably foreseeable. (Kent v Griffiths, 2000) It is hence submitted that the fraud that TJC failed to detect was an omission which was foreseeable since there are several cases of fraud in the banking industry and practitioners should have an open eye on every issue. Secondly, it must be established that there was a legal relationship between the parties that can be regarded as a relationship of proximity that will expect a duty of care from the other party. (Home Office v Dorset Yacht Club, 1970) It goes without saying that a relationship of proximity is easily established between TJC which was an auditing firm and its clients sunflower bank. The duty of care is established because sunflower bank depended on the services of TJC. Thirdly, whether taking all circumstances into consideration it would be just reasonable and fair for the law to impose a duty. (Capital v Hampshire County Council ,1997) In TJC the court will not have to struggle with imposing any duty on TJC as the relationship between TJC and Sunflower bank is one that is created by a legal contract. Breach of duty Negligence occurs where the standard expected of a person falls below that of an ordinary skilled reasonable man. (Roe v Minister of Health, 1954). In deciding whether there has been a breach of the duty of care owed the courts will be guided and persuaded by four factors. First, the court will look at the degree of risk involved where it weighs the likelihood of the harm occurring. In Haley v London Electricity Board (1964) the court held that there was a commonly known risk that ought to have been foreseen. As noted above, the risk of fraud in banking is one that has gained prominence in this era and experts and professionals should put all measures to ensure that any such frauds are avoidable before they transpire. Secondly, the court will also look at the seriousness of the harm or damage suffered. It has been observed that at times the gravity of harm or damaged suffered is so is so low that courts will throw out such claims that seek to waste the courts time. (Paris v Stepney Borough Council, 1951) The gravity of the harm and loss suffered due the actions TJC cannot be downplayed by the court. The loss of $10 million is so grave and is likely to attract the attention of any ordinary court. Thirdly, the court will consider whether it would be reasonably practicable to take any precautions to avoid the harm or loss. (Latimer v AEC Ltd, 1952) The standard here will be that of a reasonably skilled person in the same practice. Fourthly, the courts will ask if the defendants action was of any useful social purpose. (Watt v Hertfordshire County Council, 1954). Infallibly, the actions of TJC served no useful purpose. Proof of breach If Sunflower bank is to bring a claim of negligence then as the plaintiffs they have to provide evidence that will connote that the defendant failed to exercise reasonable skill and care. Nevertheless where such evidence is not available and the facts of the case clearly speak for themselves the maxim of res ipsor loquitor will apply. (Scott v London St Katherine Dock Co, 1865) Damage caused by MCJs Breach of Duty It is submitted that Sunflower bank must show that the loss of the money would not have occurred but for the defendants negligent omissions. This is referred to the But for test that seeks to establish the causal link between the damage and the defendant. The test was authored in Barnett v Chelsea Kensington Hospital (1968) where it was held that damage may at times occur not as a consequence of an act or omission of the defendant but the damage would have occurred anyway even if the or act omission did not transpire. It is advised that this argument resonates more with the defendants case and can be used as a defense. It has been argued that a foreseeable harm may at times occur in an unforeseeable manner which is an argument that TJC may borrow but such an argument does not hold water and liability will still attach as was held in Hughes v Lord Advocate (1963). However, a defendant will not be liable for a tort of negligence where the plaintiff has a weakness or a predisposition to such loss or damage. (Smith v Leech Brain Co, 1961) The foregoing submissions are brought to the attention of TJC and the three essential elements are fundamental for any claim of negligence to succeed. It is of particular significance to note that a claim of negligence is a civil action and the standard of proof is not equated to a criminal action which is beyond reasonable doubt. The standard of proof here is lower and is held to be on a balance of probability. TJC will not incur liability for negligence if they acted professionally and in a manner that has a general acceptance across Australia. (Civil Liability Act 2002 S 50(1) 3. It is apt to underscore the fact that the law of agency imposes a fiduciary duty on the agent. Succinctly, the agent is authorized by the principal to act on his behalf and this raises a legal relationship. The agency agreement between Will and farm fresh crystalizes their legal relationship. It should be borne in mind that an agent is authorized to do that which is authorized by the Principal or that which he can reasonably infer that the principal would desire him to perform. (International Harvester Company of Australia Pty Ltd v Carrigan's Hazledene Pastoral Co ,1958) From the onset it is submitted that pursuant to the agency agreement entered between farm fresh and Will, Will has an actual express authority to act on behalf of the principal. The authority is complete because it follows consent from the principal and there had been a written agreement that Will shall earn a 5% interest in the work that he will undertake on behalf of the principal. (Equiticorp Finance v BNZ(1993) Agency must not necessarily derive from consent of the principle but the law can infer that that an agency agreement existed where the parties were acting as such with the third party and the third party knew that the agent was acting for a known principal.. (Branwhite v Worcester Works Finance Ltd, 1969) It can be argued that Will had actual implied authority which while he was performing the transaction with the third party as he did not have express authority ,however, drawing from the following elements of an actual implied authority his acts were valid. First the agent was acting following the usual manner in which he performs his duties on behalf of the principal. This is referred to as the usual authority of an agent and it can be said that Will was acting in the usual way and his actions were incidental to the other acts that he has been performing for the principal. ( Hely-Hutchinson v Brayhead Ltd 1968) Second, the acts of the agent had gained the force of a custom and thus it is referred to as a customary authority. The leading case in the entire of the facts in issue and one that perhaps goes furthest is (Freeman Lockyer v Buckhurst Park Properties (Mangal) (1964). In this case, H and K formed a company to develop property and the articles of the company gave provisions for managing directors but they had not been appointed. K went ahead and engaged a company to take on some constructions but later on the company claimed that k did not have authority. It was held that the K had ostensible authority to act. The courts have also espoused that the person who is held to have ostensible authority must also have an actual express authority to act. (Crabtree-Vickers Pty Ltd v Australian Direct Mail 1975) Will had ostensible authority to act because it was the usual way of business as the principal had not objected to his actions thereby the third party continued to transact with him and furthermore he had express authority derived from the agency agreement. A more persuasive position is that, despite the fact that Will had no express authority to transact with Dairy to Go, his actions were ratified by the principal. For ratification to be held have been undertaken the following must be proven; First, the agent whose act is sought to be ratified must have been acting on behalf of the principle. (Howard Smith Co Ltd v Varawa, 1910) This was well within the knowledge of Dairy to go and the business had gone on for a considerable period of months. Secondly, the principal must have been disclosed at the time of ratification. (Trident v McNeice Bros Pty Ltd, 1988) Dairy to go knew the principle because they were aware that Will was an agent of Farm fresh. The silence of the principal does not amount to ignorance nor does it mean that he has not ratified the act. It has been held that the principal can also ratify an action by silence or inaction. (Klement v Pencoal, 2000) This argument can be borrowed and applied by the principal of Farm fresh as he can say that he was aware of the business between his agent and Dairy to go and that is why he allowed it to continue up to then. This argument crystallizes the point that indeed there was a valid and enforceable contract between Farm fresh and Dairy to Go. Undoubtedly the evidence that has been demonstrated above manifestly shows that the contract that was undertaken between Dairy to Go and Farm fresh is one that legally binds both parties and is enforceable. Indeed it has been proven that Will had authority to act on behalf of the principal albeit his authority was not expressly authorized by the principal. It is submitted that an agent can not act on his own behalf if the third party is aware of the principal. (Irvine v Union Bank of Australia, 1877) To this extent, it can also be argued that Will is entitled to earn the 5%interest because as noted above there has been a mountain of evidence to show that indeed an agency relationship existed and that Wills principle is mandated to honor the agency contract. On the hand, the principal lacks a sufficient ground to terminate the agency contract because Will acted in a manner that was recognized by law so no penalties can be imposed on him. 4. Reflective Journal The law is the art of goodness and equity, but it is the inherent nature of justice that it will not make parties in a case equally exuberant at the end of the day. However, in the eyes of the law justice is deemed to be fairness. My reference to the above has been accentuated by the fact that the contractor in question one has to agree to suffer the loss a circumstance that the construction company does not sit well with but the law is ass as the positivist school of thought will put it. The research on this question has compelled me to learn that the law of contract requires that contracts are entirely honored. In addition, the construction professionals should be careful to undertake the contract as agreed. What was intriguing more is the fact that the contractors have to pay liquidated damages. I have had the privilege to bring to my attention from the research on this question that preferably, construction contracts must entail a liquidated damage clause that serves to prevent tedious endeavors trying to calculate the amount of damages to be paid. (Kean and Caletka, 2008) Nevertheless, the absence of a liquidated damages clause is not an implication that the owner cannot apply for liquidated damages. Suffice to say, contactors should follow the proper procedure where they have foreseen an expected delay and since the law is dynamic the contract can be extended but it is very unfortunate that the law does not favor the circumstances of the contractors case in question which is has a devastating effect on them. In regards to question two the research involved was quite educative and one that its importance I cannot undermine. Professionals have a duty of care to people who their acts or omissions are like to affect and they are required to reasonably foresee such acts or omissions so as not to cause any harm. (Donoghue v. Stevenson, 1932) The famous dictum of Lord Artkin is one that sinks deep into my heart as an aspiring profession. It is prudent that I mention that this research had a wealth of case law that was interesting and whose importance to my career I cannot undermine. The case laws that I have used exemplifies that the standard of skill and care required of the profession will not be measured beyond that of an ordinary skilled man in the same practice. It is worth mentioning that a breach duty of care is followed by award of damages to the party which indeed has a deterrent effect to professionals thereby sending a sound and striking message that those who are reckless in their duties will come face to face with the sharp claws of the application of the law of Negligence. Question three, on the other hand, bestows upon me sufficient knowledge to be able to track the path of the law of agency with competency. The authority that is vested on the agent by the principle is a fundamental one and the agents should be careful not to exceed their authority. In undertaking this question it was brought to my knowledge that an agent should only proceed with an act in which the principal himself is competent to undertake. It was rather interesting to note that despite Wills lack of express authority, the law derives other authorities that approved the actions of Will. Conversely, the ratification of previously unauthorized is a principle that I carried home and could not negate its importance. Indeed a principal can right the wrongs of the agent but only to the extent that the actions are not illegal. The ability of the law to fit the circumstances in favor of Will and Farm Fresh was in my view enticing. The flexibility of the law in this research is unimaginable. I was compelled to learn that actual implied authority if different from apparent authority. Implied authority is inferred from the usual conduct of the business and actions that are incidental to the normal conduct of the agent that is allowed by expressed authority. On the other hand, apparent authority is a conduct by the principal that has led the third to believe that the agent is acting on his behalf. References Australian Development Corporation (ADC) v White Constructions (1996) 12 BCL 317. 2. Barnett v Chelsea Kensington Hospital (1968)3 All ER 1068 Bolam v Friern Hospital Management Committee (1957) 1 WLR 582 Boucaut Bay Co Ltd v Commonwealth (1927) 40 CLR 98 Branwhite v Worcester Works Finance Ltd (1969) 1 AC 552. Caparo Industries v Dickman (1990) 2 AC 605 Capital v Hampshire County Council (1997)QB 1004 Civil Liability Act 2002 CMA Assets Pty Ltd v John Holland Pty Ltd (2015)WASC217 Crabtree-Vickers Pty Ltd v Australian Direct Mail (1975)133 CLR 72. Donoghue v. Stevenson (1932)UKHL 100 Equiticorp Finance v BNZ (1993) 32 NSWLR 50 Fibrosa Spolka Akcyjna v Fairburn Lawson Combe Barbour Ltd (1943) AC 32 Freeman Lockyer v Bucklehurst Park Properties (Mangal) Pty Ltd (1964)2 QB 480 Grant v Australian Knitting Mills (1936 )A.C. 562 Haley v London Electricity Board (1964) 3 WLR 479, Hely Hutchinson v Brayhead Limited (1968) 1 QB 549 Home Office v Dorset Yacht Club (1970) AC 1004 Howard Smith and Co Limited v Varawa (1910) HCA 30 Hughes v Lord Advocate (1963) A.C. 837 (H.L.). International Harvester Company of Australia Pty Ltd v Carrigan's Hazledene Pastoral Co (1958) 100 CLR 644 Irvine v Union Bank of Australia (1877) 2 App Cas 366 J-Corp Pty Ltd v Mladenis (J-Corp) (2010) 26 BCL 106 Jerry Bennett Masonry Inc. v. Crossland Constr.Co. (2005) 171 S.W.3d 81 Keane, P.J. and A.F. Caletka, ( 2008) Delay Analysis in Construction Contracts Kent v Griffiths (2000)2 WLR 1158 Klement v Pencoal [2000] QCA 152 L Shaddock Associates Pty Ltd v Parramatta City Council [1981] HCA 59 Latimer v AEC Ltd (1952) 2 All ER 449 Nathan C, Lee C and Henry P,( 2014) Resolving Problems and Disputes on Construction. Roe v Minister of Health [1954] 2 All ER 131 South Carolina Federal Savings Bank v. Thornton-Crosby (1992) SC 423 S.E.2d 114 Trident v McNeice Bros Pty Ltd (1988) HCA 44 Paris v Stepney Borough Council (1951) 1 All ER 42, Watt v Hertfordshire County Council (1954) 1 WLR 835

The Corporate Brand Help or Hindrance (HBR Case Study and Commentary) Essay Example

The Corporate Brand: Help or Hindrance? (HBR Case Study and Commentary) Essay The Corporate Brand: Help or Hindrance? (HBR Case Study and Commentary) BY nthn0210 Each of Lilypads boutique hotels has its own sense of place and definition of customer experience. Though loyal to their favorites, guests dont visit other luxury properties in the collection or even realize theyre affiliated. To boost the lifetime value of existing customers and reach new ones, CEO Andre Cleary is thinking about positioning the hotels more directly under the corporate umbrella. The company could gain scale efficiencies and possibly increase visits†but does one brand really fit all? Four experts comment on this fictional case study. Horst Schulze, the CEO and president of the West Paces Hotel Group, says that Lilypad must build up its corporate brand to create long-term value. This would also help the company become more efficient at cross-promoting properties, offering services, and buying supplies in bulk. Jill Granoff, the executive vice president of direct brands at Liz Claiborne, says that the financial risks of putting the Lilypad name front and center may outweigh the potential rewards. The company should instead market its hotels more aggressively to travel agents and selectively acquire new properties to propel further growth. Kevin Lane Keller of Dartmouth argues that Lilypad must clarify what its brand represents before giving it any more emphasis. Rather than making significant changes in the rooms themselves, which could weaken the individual brands, management should coordinate behind the scenes to improve cross-sell numbers. Jez Frampton, the global CEO of the consultancy Interbrand, thinks Andre should systematically examine the brand in terms of Lilypads customers and culture. That means conducting market research and moving away from the current warlord approach of managing each property as a separate fiefdom. We will write a custom essay sample on The Corporate Brand: Help or Hindrance? (HBR Case Study and Commentary) specifically for you for only $16.38 $13.9/page Order now We will write a custom essay sample on The Corporate Brand: Help or Hindrance? (HBR Case Study and Commentary) specifically for you FOR ONLY $16.38 $13.9/page Hire Writer We will write a custom essay sample on The Corporate Brand: Help or Hindrance? (HBR Case Study and Commentary) specifically for you FOR ONLY $16.38 $13.9/page Hire Writer

Spelling Tips Our 10 “Most Wanted” Homophones

Spelling Tips Our 10 â€Å"Most Wanted† Homophones Spelling Tips: Our 10 â€Å"Most Wanted† Homophones Homophones- i.e., words that sound the same but differ in spelling and meaning- can cause a lot of confusion when you’re not sure which term to use in your written work. Some mix-ups are definitely more common than others, though, so here’s our list of ten prominent â€Å"reoffenders.† Keep an eye out for them when you’re next writing something! 10. Than/Then Only one letter separates these terms, but each one has a distinct meaning. â€Å"Then† is used when referring to time: Call me at eight. I’ll be ready by then. Or when discussing consequences: If you struggle with spelling, then you might want to hire a proofreader! â€Å"Than,† meanwhile, is used primarily for making comparisons: I’m better at grammar than spelling. 9. Hear/Here â€Å"Hear† and â€Å"here† are very different words: while â€Å"hear† means â€Å"sense a sound† or â€Å"listen,† â€Å"here† means â€Å"in this place.† Keep in mind that â€Å"hear† contains â€Å"ear,† which is what you listen with! 8. Affect/Effect These are very easy to confuse, since both refer to change. The important distinction is that â€Å"affect† is a verb (i.e., the act of changing something), but â€Å"effect† is usually a noun (i.e., the result). 7. Where/Were/We’re Although they look similar on the page, you won’t want to confuse these terms in your work. â€Å"Where† refers to locations, â€Å"were† is the past tense of â€Å"are,† and â€Å"we’re† is short for â€Å"we are.† 6. Our/Are Mixing these up is common if English isn’t your first language, as they sound similar despite having very different meanings: â€Å"our† is a possessive pronoun meaning â€Å"belonging to us,† but â€Å"are† is a present tense form of the verb â€Å"to be.† 5. Now/Know In this case, the words look similar but are pronounced differently, as well as being importantly distinct in their use. â€Å"Now† means â€Å"at this time,† while â€Å"know† is a verb meaning â€Å"understand.† 4. There/Their/They’re Like â€Å"where,† â€Å"were† and â€Å"we’re,† these homophones are commonly confused due to being similarly spelled. To ensure clarity, remember that â€Å"there† means â€Å"in that place,† â€Å"their† means â€Å"belonging to them,† and â€Å"they’re† is an abbreviation of â€Å"they are.† 3. It’s/Its Although apostrophes are often used to indicate possession, the possessive pronoun â€Å"its† doesn’t need one. If you’re forming a contraction of â€Å"it is† or â€Å"it has† (i.e., â€Å"it’s†), however, you should use an apostrophe to show that letters have been omitted. 2. Too/To Another common error is mixing up â€Å"too† (an adverb meaning â€Å"also† or â€Å"excessively†) and â€Å"to† (a preposition that often indicates direction or duration, as well as being used in combination with infinitive verbs). Even if you know the difference between these homophones, keep in mind that it’s easy to make a typo! 1. Your/You’re At the top of our list of â€Å"most wanted† homophones are â€Å"your† and â€Å"you’re,† simply because they’re so commonly mistaken in day-to-day writing (just check social media if you don’t believe us). Remember, though, that â€Å"your† is a possessive pronoun that means â€Å"belonging to you† (e.g., â€Å"Your spelling is outstanding!†), while â€Å"you’re† is a contraction of â€Å"you are† (e.g., â€Å"You’re a great speller!). Believed to be armed and dangerous. Report to your local proofreader immediately.

Financial Bubbles Assignment Example | Topics and Well Written Essays - 500 words

Financial Bubbles - Assignment Example The increase in demand pushed the price of this flower to the sky, leading to market maneuvers of artificial scarcity and artificial price hike. As they say, a bubble bursts when the investors start minting money out of it. Soon when people realized this situation they started selling their stocks and the large contractor started dishonoring their contracts thus resulting in the crash of the bulb market and the bubble burst/ Tech Bubble – 1999 This bubble is also known as the Dot.Com bubble. It happened when the technology market boomed and the internet business was thought to be the star of future profit. NASDAQ soared and so did these internet companies. But then in the late 1999 and the beginning of 2000 saw a crash of this internet bubble when the companies themselves could not take the over burden of these demands and showed losses that very high and pushed the index to a shocking low level, thus resulting in a bubble burst.

Holistic Conception of Marketing Essay Example | Topics and Well Written Essays - 750 words

Holistic Conception of Marketing - Essay Example Ulrich and Ellison (1999. pp656) emphasized that holistic customer requirements can impact even the fundamentals of a firm - the organizational architectures and product architectures. They argued that more holistic requirements from customers will require more integrated product development organizations with some heavyweight project managers that have the capability to translate "hard to articulate" customer requirements into technical specifications of the components of products. In the modern era of stringent global competitiveness, Customer Relationship Management (CRM) has taken prominent space in the global context as it has evolved as proven tool for customer retention and customer share development. As argued by Verhoef (2003. pp35), achieving positive customer relationship perceptions through satisfaction, payment equity and affective commitment are the primary objectives of customer relationship management. However, Garcia-Murillo and Annabi (2002. pp876-879) argued that a very crucial system called "Customer Knowledge Management (CKM)" is largely ignored in the modern marketing world which is critical to achieve holistic customer information to achieve the global competitiveness. They presented a framework in which customer knowledge needs to be a part of integrated firm knowledge system comprising of knowledge of suppliers, products, industry, employees, operations and competitors. This system can ensure a much bigger picture of customer needs and to the level & effectiveness the organization can fulfil them by collaborating information from various knowledge bases - plants & machineries capacities & capabilities, people competencies, production flows, quality controls & assurance, legal issues, uniqueness aspects such that competitors cannot copy them so easily, etc. The authors emphasized that customer knowledge management is important to arrive at better & timely design of new products & services that can be accepted by the customers, generate e arly warnings about reducing competencies of the company, improve competitive intelligence, achieve synergy within the organization towards meeting customer needs and demonstrate commitment to customer. They established differences between CRM and CKM whereby CKM is presented as two way system that can capture customer's ideas, concepts, experiences and improvement areas. It justifies the role of holistic customer information capturing as discussed by Svensson (2001. pp95-101) and is very much applicable in the modern world of global marketing opportunities. Conclusion: In this short essay, the author presented that Customer Knowledge Management is the modern system that can ensure capturing of holistic view of customer information for firms to develop customer oriented products and market them even at global scales. Reference List: Garcia-Murillo, M and

Different ethnic groups in Nigeria Essay Example for Free

Different ethnic groups in Nigeria Essay Nigeria is very rich in culture. Various ethnic groups in Nigeria have their own culture. The Durbar festival in the various emirates of the North of Nigeria symbolizes strength and dexterous skills in riding of horses. Durbars are called up during religious festivals like Id el Fitri and Id el Kabir. They are also called up during installation ceremonies of the Emirs. They are also called up during installation ceremonies of the Emirs. The Durbars serve as entertainment for very important visitors. Durbars are also called up during the anniversary of the birth of Prophet Mohammed (Id el Maulud). The horses are colorfully adorned and the horse riders are in procession. The riders are dressed in aristocratic regalia blowing bugles and trumpets accompanied by drumming and dancing. They make displays in riding the horses and come to abrupt halt to salute and pledge loyalty to Emirs. Also in Kano and Katsina, there is the Kalankwa Festival, which usually comes at the end of the harvest season. At the Kalankwa Festival, traditional boxing, wrestling, music and dances of different types are performed. In Benue State the Eje Alekwu Festival is an annual festival celebrated to relate with the ancestral gods of Idoma land. Before the Eje Alekwu masquerades appear, sacrifices are offered to the gods to appease them and appeal for protection for the future. The festival is celebrated by different masquerades to represent various ancestral characters and spirits of the ancestors. The Tiv Day is a national day for the Tiv all over the country. During the festival the people send delegates from ever town to converge at the Tor Tivs palace for deliberations on developments strategy among the Tiv local government areas. At the same time old and offensive laws are abrogated and new ones made for the people for peace and progress. New traditional titles are conferred on deserving sons and daughters of the land. It is held annually on the 19th of September to coincide with the day the first Tor Tiv was installed in 1946. In Nigeria, boat regattas are part of the socio-cultural life of the riverine people in the Niger Delta. The boats do not have engines but they are rowed manually with traditional paddles by over twenty to fifty people on board depending on the size of the boat. Boat regattas are special festival to celebrate attachment of the people to water, as fishing is their dominant occupation. When there is a bountiful catch and sea yields boat regattas are held that year. In Bonny, River State we have the masquerade group known as Owogbo. Each of the major houses in the Bonny Kingdom has their end of the fishing season locally known as Fungu. The masquerade is the traditional way of paying homage to the sea gods. They carry a carved shellfish. The masquerade is usually brightly colored with locally made fabrics. Both men and women take part in the dancing. Among the Efik and some Ibibio tribes of Cross River and Akwa Ibom States of Nigeria the Ekpe Secret Society occupies a significant position and functional as an instrument for law and order. Mention of Ekpe brings fear and terror to the uninitiated. The word Epke literally means leopard and its masquerade are so named for its multi-colored costume. Membership of Ekpe Society is seen as a status symbol. The Ekemini Theatre Troupe of Akwa Ibom State captivates local and international audiences through a galaxy of choreographed dance drama. Traditional instruments are used. The group has fused many of the folk tale and culture of Akwa Ibom and neighboring states with contemporary dance styles. The star performer of the group is Ofonine Felix Essien popularly known as Udo Maryam who at the age of four started playing many traditional instruments. Among the Ibos, festivals play an important role in the social cohesion. There are such festivals as the Ofala and the new yam festival. The spices of these festivals are cultural dances and drama while masquerades add mythical splendor. The Atilogu dances are a very popular form of cultural display in Igoland. It comprised of series of systematic acrobatic dance  actions like twisting, somersaulting and building of human pyramids. During joyful occasions the dancers dress in bright colors but on sorrowful occasion they dress in dark attires and their movements are slow and mournful. Because of the rich mix of ethnic groups in Ondo state. It presents a wide variety of culture and festivals. Prominent among them are the Bata Dance, the Ititum Maiden Dance, Ajabore, Igogo, Oluwa and Ogun festivals. Animals such as dogs are offered to the god of iron, Ogun during the celebration. The Akoo and Ekiti areas are well known for cloth weaving while Owo is popular for its special cloth or royalty. In Lagos State, the eyo masquerade is of traditional importance and it has a historical background. It is the pride of the Oba, Chiefs and people of Lagos. It was first performed in Ikoyi in the 18th century as a traditional play. It now features during special ceremonies. Eyo is hooded and robed in flowing white gowns. These cover his hands and feet. It carries a special staff known as the Opabata. The Eyo is barefooted and spectators who want to see the Eyo must be barefooted in order not t incur the anger of the masquerade. The offender is beaten with Opabata. The Benin Kingdom, the best-known center of civilization in the pre-colonial days, has the oba as the traditional head. The Igu festival is celebrated annually in December for the Oba and his subjects. It is a combination of nine principal ceremonies during which animals especially goats are sacrificed. The celebrants dress in their finest attires and join in songs and dances. I find Nigeria culture interesting in that it unites the people and also leads to progress.